Orion Group Holdings Inc

Previous wording

As more fully described in “Insurance and Bonding” under “Item 1. Business,” we are generally required to post bonds in connection with government and certain private sector contracts to ensure job completion. We have entered into bonding agreements with two large multinational surety companies, which act as surety, issue bid bonds, performance bonds and payment bonds, and obligate themselves upon other contracts of guaranty required by us in the day-to-day operations of our business. However, our sureties are not obligated under the bonding agreements to issue bonds for us, and bonding decisions are made on a case-by-case basis. We are currently near our bonding capacity limits and may not be able to maintain a sufficient level of bonding capacity in the future, which could preclude us from being able to bid for certain contracts and successfully contract with certain customers, or cause us to have to increase our letter of credit utilization in lieu of bonds, thereby reducing available borrowing capacity under our Credit Agreement (as defined below, in Risk Factors Relating to Our Indebtedness). In addition, the conditions of the bonding market may change, increasing our costs of bonding or restricting our ability to get new bonding, which could have a material adverse effect on our business, operating results and financial condition

Current wording

As more fully described in “Insurance and Bonding” under “Item 1. Business,” we are generally required to post bonds or other security in connection with government and certain private sector contracts to ensure job completion. We have entered into bonding agreements with several large multinational surety companies, which act as surety, issue bid bonds, performance bonds and payment bonds, and obligate themselves upon other contracts of guaranty required by us in the day-to-day operations of our business. However, our sureties are not obligated under the bonding agreements to issue bonds for us, and bonding decisions are made on a case-by-case basis. We are bidding on increasingly complex, larger jobs for customers who require significant bonds. While we had approximately $500 million of available bonding capacity as of December 31, 2024, we may not be able to maintain a sufficient level of bonding capacity in the future which could preclude us from being able to bid for certain contracts and successfully contract with certain customers. In addition, the conditions of the bonding market may change, increasing our costs of bonding or restricting our ability to get new bonding, which could have a material adverse effect on our business, operating results and financial condition.

Previous wording

administration, performance and accounting. Many of these contracts include express or implied certifications of compliance with applicable laws and contract provisions. Any violations of these regulations could bring about litigation, including the possibility of qui tam (“whistleblower”) litigation brought by private individuals on behalf of the government under the Federal Civil False Claims Act, and could cause termination of other existing government contracts and result in the loss of future government contracts. Due to the significant competition in the marketplace and the level of regulations on government contracts, we could suffer reductions in new projects and see lower revenues and profit margins on those projects, which could have a material adverse effect on our business, operating results and financial condition.

Current wording

Government funding for public works projects is limited, thus creating a highly competitive environment for the limited number of public projects available. Reduced levels of, or delays in, government funding cause delays in project lettings and result in intense competition and pricing pressure for such projects. In addition, government contracts are subject to specific procurement regulations, contract provisions and a variety of regulatory requirements relating to their formation, administration, performance and accounting. Many of these contracts include express or implied certifications of compliance with applicable laws and contract provisions. Any violations of these regulations could bring about litigation, including the possibility of qui tam (“whistleblower”) litigation brought by private individuals on behalf of the government under the Federal Civil False Claims Act, and could cause termination of other existing government contracts and result in the loss of future government contracts. Due to the significant competition in the marketplace and the level of regulations on government contracts, we could suffer reductions in new projects and see lower revenues and profit margins on those projects, which could have a material adverse effect on our business, operating results and financial condition.

Previous wording

Ourbusiness, operating results and financial condition could be materially and adversely affected if a public health epidemic or pandemic or other contagious outbreak, such asthe coronavirus (“COVID-19”) pandemic, interferes with our ability, or that of our employees, contractors, suppliers, customers and other business partners to perform our and their respective responsibilities and obligations relative to the conduct of our business.

Current wording

Ourbusiness, operating results and financial condition could be materially and adversely affected if a public health epidemic or pandemic or other contagious outbreak interferes with our ability, or that of our employees, contractors, suppliers, customers and other business partners to perform our and their respective responsibilities and obligations relative to the conduct of our business.

Previous wording

Our concrete segment depends on continued growth in population in our geographic market areas in Texas and most recently in Florida to support residential and nonresidential construction. A growing population generates economic growth and expansion. If the population decreases or slows in growth, it may adversely affect economic growth and ultimately limit the need for residential and nonresidential construction services in the areas we currently perform services.

Current wording

Our concrete segment depends on continued growth in population in our geographic market areas in Texas and most recently in Florida to support commercial development. A growing population generates economic growth and expansion. If the population decreases or slows in growth, it may adversely affect economic growth and ultimately limit the need for construction services in the areas we currently perform services.

Previous wording

Moreover, even when the underlying economic fundamentals that ordinarily drive the level of construction activity are strong, the level of economic activity in such markets may be suppressed during inflationary periods that are accompanied by increasing interest rates. If the Federal Reserve Board resumes increasing interest rates to respond to re-emerging inflation concerns, our concrete business could see a reduction in demand.

Current wording

Moreover, even when the underlying economic fundamentals that ordinarily drive the level of construction activity are strong, the level of economic activity in such markets may be suppressed during inflationary periods that are accompanied by increasing interest rates. If the Federal Reserve Board resumes increasing interest rates to respond to re-emerging inflation concerns, or otherwise maintains high interest rates, commercial development could slow and our concrete business could see a reduction in demand.

Previous wording

Commodity prices can affect our customers in a number of ways. For example, for those customers that produce commodity products such as oil, gas, concrete, steel products, fluctuations in price can have a direct effect on their profitability and cash flow and, therefore, their willingness to continue to invest or make new capital investments. To the extent commodity prices decline or fluctuate and our customers defer new investments or cancel or delay existing projects, the demand for our services decreases, which may have a material adverse impact on the business, financial condition, and results of operations.

Current wording

Commodity prices can affect our customers in a number of ways. For example, for those customers that produce commodity products such as oil, gas, concrete, or steel products, fluctuations in price can have a direct effect on their profitability and cash flow and, therefore, their willingness to continue to invest or make new capital investments. To the extent commodity prices decline or fluctuate and our customers defer new investments or cancel or delay existing projects, the demand for our services decreases, which may have a material adverse impact on our business, financial condition, and results of operations.

Previous wording

Commodity prices can also strongly affect the costs of projects. We use concrete and steel as well as diesel fuel and other petroleum-based products to operate our equipment used in our construction contracts. Fluctuations in supplies relative to demand and other factors can cause unanticipated increases in their cost. Rising commodity prices can negatively impact the potential returns on projects that are planned, as well as those in progress, and result in customers deferring new investments or canceling or delaying existing projects. The short-term nature of the majority of our projects typically

Current wording

Commodity prices can also strongly affect the costs of projects. We use concrete and steel as well as diesel fuel and other petroleum-based products to operate our equipment used in our construction contracts. Fluctuations in supplies relative to demand and other factors can cause unanticipated increases in their cost. Rising commodity prices can negatively impact the potential returns on projects that are planned, as well as those in progress, and result in customers deferring new investments or canceling or delaying existing projects. The short-term nature of the majority of our projects typically protects us from these potential price increases, however, if we are unable to procure commodities for completion of our projects at estimated prices due to rising commodity prices, our margins may erode on certain in progress or future projects.

Previous wording

As of December 31, 2023, we had a backlog of work to be completed on contracts totaling approximately $602.5 million in our marine segment and approximately $159.7 million in our concrete segment. Backlog includes new awards, which represent the potential revenue value realizable pursuant to new project commitments received by us during a given period.

Current wording

As of December 31, 2024, we had a backlog of work to be completed on contracts totaling approximately $582.8 million in our marine segment and approximately $146.3 million in our concrete segment. Backlog includes new awards, which represent the potential revenue value realizable pursuant to new project commitments received by us during a given period.

Previous wording

A portion of the work performed under our contracts is performed by third-party subcontractors we hire. We also rely on third-party equipment manufacturers or suppliers to provide much of the materials used for projects. If we are unable to hire qualified subcontractors or find qualified equipment manufacturers or suppliers, our ability to successfully complete a project could be impaired. If we are not able to locate or engage qualified third-party subcontractors or the amount we are required to pay for subcontractors or equipment and supplies exceeds what we have estimated, especially in a lump-sum or a fixed-price contract, we may suffer losses on these contracts. If a subcontractor, supplier, or manufacturer fails to provide services, supplies or equipment as required under a contract for any reason, we may be required to source these services, equipment or supplies to other third parties on a delayed basis or on less favorable terms, which could impact contract profitability. There is a risk that we may have disputes with our subcontractors relating to, among other things, the quality and timeliness of work performed, customer concerns about the subcontractor, or our failure to extend existing task orders or issue new task orders under a contract. In addition, faulty workmanship, equipment or materials could impact the overall project, resulting in claims against us for failure to meet required project specifications.

Current wording

A portion of the work performed under our contracts is performed by third-party subcontractors we hire. We also rely on third-party equipment manufacturers or suppliers to provide much of the materials used for projects. If we are unable to hire qualified subcontractors or find qualified equipment manufacturers or suppliers, our ability to successfully complete a project could be impaired. If we are not able to locate or engage qualified third-party subcontractors or the amount we are required to pay for subcontractors or equipment and supplies exceeds what we have estimated, especially in a lump-sum or a fixed-price contract, we may suffer losses on these contracts. If a subcontractor, supplier, or manufacturer fails to provide services, supplies or equipment as required under a contract for any reason, we may be required to source these services, equipment or supplies to other third parties on a delayed basis or on less favorable terms, which could impact contract profitability. There is a risk that we may have disputes with our subcontractors relating to, among other things, the quality and timeliness of work performed, customer concerns about the subcontractor, or our failure to extend existing

Previous wording

We have traditionally owned the majority of the equipment used in our projects, and we do not bid on contracts for which we do not have, or cannot quickly procure, whether through construction, acquisition or lease, the necessary equipment to complete projects. We are capable of building much of the specialized equipment used in our projects, including dayboats, tenders and dredges. To the extent that we are unable to buy or build equipment necessary for our needs, either due to a lack of available funding or equipment shortages in the marketplace, we may be forced to rent equipment on a short-term basis, which could increase the costs of completing contracts, thereby reducing contract profitability. In addition, our equipment requires continuous maintenance, which we primarily provide through our own repair facilities, as well as certification by the U.S. Coast Guard for certain marine segment assets. If we are unable to continue to maintain the equipment in our fleet or are unable to obtain the requisite certifications, we may be forced to obtain third-party repair services, be unable to use our uncertified equipment or be unable to bid on contracts, which could have a material adverse effect on our business, operating results and financial condition.

Current wording

We do not bid on contracts for which we do not have, or cannot quickly procure, whether through construction, acquisition or lease, the necessary equipment to complete projects. We are capable of building much of the specialized equipment used in our projects, including dayboats, tenders and dredges. To the extent that we are unable to buy or build equipment necessary for our needs, either due to a lack of available funding or equipment shortages in the marketplace, we may be forced to rent equipment on a short-term basis, which could increase the costs of completing contracts, thereby reducing contract profitability. In addition, our equipment requires continuous maintenance, which we primarily provide through our own repair facilities, as well as certification by the U.S. Coast Guard for certain marine segment assets. If we are unable to continue to maintain the equipment in our fleet or are unable to obtain the requisite certifications, we may be forced to obtain third-party repair services, be unable to use our uncertified equipment or be unable to bid on contracts, which could have a material adverse effect on our business, operating results and financial condition.

Previous wording

Our marine segment operates in jurisdictions outside of the U.S. and we intend to expand our operations to more jurisdictions outside of the U.S.

Current wording

Our marine segment operates in jurisdictions outside of the U.S. and we intend to continue expanding our operations to more jurisdictions outside of the U.S.

Previous wording

Our marine segment, which accounted for 55.6%, 45.3% and 43.9% of our contract revenues for the years ended December 31, 2023, 2022 and 2021, respectively, has a significant portion of those operations performed outside of the U.S. For the years ended December 31, 2023, 2022 and 2021, our international operations generated approximately 5.1%, 0.9% and 0.5% of our contract revenues, respectively. The Bahamas represented our largest international market outside of the U.S., with our Bahamian operations representing 5.1% of our contract revenues for the year ended December 31, 2023, including 11.0% of our total cash balance at December 31, 2023. In addition, we intend to expand our operations to other areas outside the U.S. in the future. International operations are subject to a number of risks and uncertainties that could negatively impact our results from operations, including:

Current wording

Our marine segment, which accounted for 65.5%, 55.6% and 45.3% of our contract revenues for the years ended December 31, 2024, 2023 and 2022, respectively, has a significant portion of those operations performed outside of the U.S. For the years ended December 31, 2024, 2023 and 2022, our international operations generated approximately 7.4%, 5.1% and 0.9% of our contract revenues, respectively. The Bahamas represented our largest international market outside of the U.S., with our Bahamian operations representing 7.4% of our contract revenues for the year ended December 31, 2024, including 1.8% of our total cash balance at December 31, 2024. In addition, we intend to expand our operations to other areas

Previous wording

Furthermore, due to a variety of factors such as increases in claims and projected significant increases in medical costs, our insurance premiums may increase in the future and we may not be able to obtain similar levels of insurance on reasonable terms, or at all. Any such inadequacy of, or inability to obtain, insurance coverage at acceptable rates, or at all, could have a material adverse effect on our business, operating results and financial condition.

Current wording

Furthermore, due to a variety of factors such as increases in claims, the rise of “nuclear verdicts” in some of the jurisdictions in which we operate and projected significant increases in medical costs, our insurance premiums may increase in the future and we may not be able to obtain similar levels of insurance on reasonable terms, or at all. Any such inadequacy of, or inability to obtain, insurance coverage at acceptable rates, or at all, could have a material adverse effect on our business, operating results and financial condition.

Previous wording

Insurance liabilities are difficult to assess and quantify due to unknown factors, including the severity of an injury, the determination of our liability in proportion to other parties, the number of incidents not reported and the effectiveness of our safety program. If we were to experience insurance claims or costs above our estimates, we might be required to use working capital to satisfy these costs rather than to maintain or expand our operations. To the extent that we experience a

Current wording

Insurance liabilities are difficult to assess and quantify due to unknown factors, including the severity of an injury, the determination of our liability in proportion to other parties, the number of incidents not reported and the effectiveness of our safety program. If we were to experience insurance claims or costs above our estimates, we might be required to use working capital to satisfy these costs rather than to maintain or expand our operations. To the extent that we experience a material increase in the frequency or severity of accidents or workers’ compensation and health claims, or unfavorable developments on existing claims, our operating results and financial condition could be materially and adversely affected.

Previous wording

Our marine infrastructure construction, salvage, demolition, dredging and dredge material disposal activities are subject to stringent and complex federal, state and local environmental laws and regulations, including those concerning air emissions, water quality, solid waste management, and protection of certain marine and bird species, their habitats, and wetlands. We may incur substantial costs in order to conduct our operations in compliance with these laws and regulations. For instance, we may be required to obtain, maintain and comply with permits and other approvals (as well as those obtained for projects by our customers) issued by various federal, state and local governmental authorities; limit or prevent releases of materials from our operations in accordance with these permits and approvals; and install pollution control equipment. In addition, compliance with environmental laws and regulations can delay or prevent our performance of a particular project and increase related project costs. Moreover, new, stricter environmental laws, regulations or enforcement policies, including those imposed in response to climate change, could be implemented that significantly increase our compliance costs, or require us to adopt more costly methods of operation.

Current wording

emissions, water quality, solid waste management, and protection of certain marine and bird species, their habitats, and wetlands. We may incur substantial costs in order to conduct our operations in compliance with these laws and regulations. For instance, we may be required to obtain, maintain and comply with permits and other approvals (as well as those obtained for projects by our customers) issued by various federal, state and local governmental authorities; limit or prevent releases of materials from our operations in accordance with these permits and approvals; and install pollution control equipment. In addition, compliance with environmental laws and regulations can delay or prevent our performance of a particular project and increase related project costs. Moreover, new, stricter environmental laws, regulations or enforcement policies, including those imposed in response to climate change, could be implemented that significantly increase our compliance costs, or require us to adopt more costly methods of operation.

Previous wording

The demand for port construction, maintenance infrastructure services and dredging may be vulnerable to downturns in the economy generally and in the marine transportation industry specifically. The amount of capital expenditures on port facilities and marine infrastructure in our markets is affected by the actual and anticipated shipping and vessel needs of the economy in general and in our geographic markets in particular. If the general level of economic activity deteriorates, our customers may delay or cancel expansions, upgrades, maintenance and repairs to their infrastructure. A number of other factors, including the financial condition of the shipping industry, could adversely affect our customers and their ability or willingness to fund capital expenditures in the future. During downturns in the U.S. or world economies, the

Current wording

The demand for port construction, maintenance infrastructure services and dredging may be vulnerable to downturns in the economy generally and in the marine transportation industry specifically. The amount of capital expenditures on port facilities and marine infrastructure in our markets is affected by the actual and anticipated shipping and vessel needs of the economy in general and in our geographic markets in particular. If the general level of economic activity deteriorates, our customers may delay or cancel expansions, upgrades, maintenance and repairs to their infrastructure. A number of other factors, including the financial condition of the shipping industry, could adversely affect our customers and their ability or willingness to fund capital expenditures in the future. During downturns in the U.S. or world economies, the anticipated port usage in our geographic markets may decline, resulting in less port construction, upgrading and maintenance. As a result, demand for our services could substantially decline for extended periods.

Previous wording

The Foreign Dredge Act of 1906, the Jones Act, the Shipping Act of 1984 and the Vessel Documentation Act require vessels engaged in the transport of merchandise or passengers between two points in the United States or dredging in the navigable waters of the United States to be owned and controlled by United States citizens. The United States citizen ownership and control standards require the vessel-owning entity to be at least 75% U.S. citizen-owned, thus restricting foreign ownership interests in the entities that directly or indirectly own the vessels which we operate. Ifwe were to seek to sell any portion of our marine segment that owns any of these vessels, we may have fewer potential purchasers, since some potential purchasers might be unable or unwilling to satisfy the foreign ownership restrictions described above; additionally, any sales of certain of our larger vessels to foreign buyers would be subject to approval by the U.S. Maritime Administration. As a result, the sales price for that portion of our marine segment may not attain the amount that could be obtained in an unregulated market.

Current wording

The Foreign Dredge Act of 1906, the Jones Act, the Shipping Act of 1984 and the Vessel Documentation Act require vessels engaged in the transport of merchandise or passengers between two points in the United States or dredging in the navigable waters of the United States to be owned and controlled by United States citizens. The United States citizen ownership and control standards require the vessel-owning entity to be at least 75% U.S. citizen-owned, thus restricting foreign ownership interests in the entities that directly or indirectly own the vessels we operate. Ifwe were to seek to sell any portion of our marine segment that owns any of these vessels, we may have fewer potential purchasers, since some potential purchasers might be unable or unwilling to satisfy the foreign ownership restrictions described above; additionally, any sales of certain of our larger vessels to foreign buyers would be subject to approval by the U.S. Maritime Administration. As a result, the sales price for that portion of our marine segment may not attain the amount that could be obtained in an unregulated market.

Previous wording

Our concrete segment, which accounted for 44.4%, 54.7% and 56.1% of our contract revenues for the years ended December 31, 2023, 2022 and 2021, respectively, is concentrated in the metropolitan areas of the State of Texas, particularly Houston and Dallas. Given this concentration, general economic conditions, regulatory changes, changes in demographics, material costs, labor conditions, competition and other conditions that affect those metropolitan areas or the State of Texas may have a disproportionate impact on the performance of our concrete segment. In addition, our operations in Texas may make us more susceptible to natural disasters, including hurricanes, tornadoes and flooding.

Current wording

Our concrete segment, which accounted for 34.5%, 44.4% and 54.7% of our contract revenues for the years ended December 31, 2024, 2023 and 2022, respectively, is concentrated in the metropolitan areas of the State of Texas, particularly Houston and Dallas. Given this concentration, general economic conditions, regulatory changes, changes in demographics, material costs, labor conditions, competition and other conditions that affect those metropolitan areas or the State of Texas may have a disproportionate impact on the performance of our concrete segment. In addition, our operations in Texas may make us more susceptible to natural disasters, including hurricanes, tornadoes and flooding.

Previous wording

Our revenues are generated from project-based work. It is generally very difficult to predict the timing and source of awarded contracts. The selection of, timing of, or failure to obtain projects, delays in awards of projects, the rebidding or termination of projects due to budget overruns, or the cancellations of projects or delays in completion of contracts could result in the under-utilization of our assets and reduce our cash flows and profitability. Even if we are awarded contracts, we face additional risks that could affect whether, or when, work will begin. For example, some of our contracts are subject to financing and other contingencies that may delay or result in termination of projects. This may make it difficult to match workforce size and equipment location with contract needs. In some cases, we may be required to bear the cost of a readily available workforce and fleet of equipment that is larger than needed at the time, resulting in unpredictability in our cash flow, expenses and profitability. If an expected contract award or the related notice to proceed is delayed or not received, we could incur substantial costs without receipt of any corresponding revenues. Delays by our customers in obtaining required approvals and permits for their infrastructure projects may delay their awarding contracts for those projects and, once awarded, the ability to commence construction under those contracts. Moreover, construction projects for which our services are contracted may require significant expenditures by us prior to receipt of relevant payments by a customer and may expose us to potential credit risk if such customer should encounter financial difficulties. Such expenditures could reduce our cash flows and necessitate increased borrowings under our Credit Agreement. Finally, the winding down or completion of work on significant projects that were active in previous periods will reduce our revenue and earnings if such significant projects have not been replaced in the current period. From time to time, we may publicly provide earnings or other forms of guidance, which reflect our predictions about future revenue, operating costs and capital structure, among other factors. Any such predictions may be impacted by these factors as well as others that are beyond our control and might not turn out to be accurate.

Current wording

flow, expenses and profitability. If an expected contract award or the related notice to proceed is delayed or not received, we could incur substantial costs without receipt of any corresponding revenues, or the revenues could appear in periods later than expected. Delays by our customers in obtaining required approvals and permits for their infrastructure projects may delay their awarding contracts for those projects and once awarded, the ability to commence construction under those contracts. Moreover, construction projects for which our services are contracted may require significant expenditures by us prior to receipt of relevant payments by a customer and may expose us to potential credit risk if such customer should encounter financial difficulties. Such expenditures could reduce our cash flows and necessitate increased borrowings under our Credit Agreement. In addition, a change in the timing of a construction project may impact future revenue. If a project is delayed, revenue that we expect to receive may appear in periods later than we initially expected, which may impact the accuracy of our guidance. Finally, the winding down or completion of work on significant projects that were active in previous periods will reduce our revenue and earnings if such significant projects have not been replaced in the current period. From time to time, wemay publicly provide earnings or other forms of guidance, which reflect our predictions about future revenue, operating costs and capital structure, among other factors. Any such predictions may be impacted by these factors as well as others that are beyond our control and might not turn out to be accurate.

Previous wording

On February 4, 2022, U.S. President Biden signed Executive Order 14063, which provided that, with certain exceptions, government contractors and subcontractors working on federal construction projects that are estimated to cost the U.S. government at least $35 million must become a party to a project labor agreement with one or more appropriate labor organizations. On December 22, 2023, the U.S. Federal Acquisition Regulatory Council issued a final rule consistent with the executive order, which went into effect on January 22, 2024. In the event our operations are determined not to satisfy any of the exceptions of the rule or the government otherwise determines that our operations with respect to any future federal project must comply with the rule, then we may be required to enter into project labor agreements which would be disruptive to our operations and could have a material adverse effect on our business, operating results and financial condition.

Current wording

On February 4, 2022, former U.S. President Biden signed Executive Order 14063, which provided that, with certain exceptions, government contractors and subcontractors working on federal construction projects that are estimated to cost the U.S. government at least $35 million must become a party to a project labor agreement with one or more appropriate labor organizations. On December 22, 2023, the U.S. Federal Acquisition Regulatory Council issued a final rule consistent with the executive order, which went into effect on January 22, 2024. On January 21, 2025, the United States Court of Federal Claims upheld a challenge to the validity of the final rule. In the event the rule is ultimately determined by a high court to be valid and our operations are determined not to satisfy any of the exceptions of the rule or the government otherwise determines that our operations with respect to any future federal project must comply with the rule, then we may be required to enter into project labor agreements which would be disruptive to our operations and could have a material adverse effect on our business, operating results and financial condition.

Previous wording

Only a small percentage of our marine segment workforce, located in the Pacific Northwest and Alaska, is currently unionized. If at any time, a majority of our employees unionized, it could limit the flexibility of the workforce and could result in demands that might increase our operating expenses and adversely affect our profitability. Each of our different employee groups could unionize at any time and would require separate collective bargaining agreements. If any group of our employees were to unionize and we were unable to agree on the terms of their collective bargaining agreement or we were to experience widespread employee dissatisfaction, we could be subject to work slowdowns or stoppages. In addition, we may be subject to disruptions by organized labor groups protesting our non-union status. Any of these events would be disruptive to our operations and could have a material adverse effect on our business, operating results and financial condition.

Current wording

Only a small percentage of our marine segment workforce, located in the Pacific Northwest and Alaska, is currently unionized. If at any time, a majority of our employees unionized, it could limit the flexibility of the workforce and could result in demands that might increase our operating expenses and adversely affect our profitability. Each of our different employee groups could unionize at any time and would require separate collective bargaining agreements. If any group of our employees were to unionize and we were unable to agree on the terms of their collective bargaining agreement or we were to experience widespread employee dissatisfaction, we could be subject to work slowdowns or stoppages. In addition, we may be subject to disruptions by organized labor groups protesting our non-union status. Any of these events would be

Previous wording

For example, in the normal course of business, we are a defendant in various personal injury lawsuits. We maintain insurance to cover claims that arise from injuries to our workforce subject to a deductible. During 2023, we recorded $1.0 million of expense for our self-insured portion of these liabilities. We believe our recorded self-insurance reserves represent our best estimate of the outcomes of these claims. Should negative trends persist, we could be negatively impacted in the future.

Current wording

For example, in the normal course of business, we are a defendant in various personal injury lawsuits. We maintain insurance to cover claims that arise from injuries to our workforce subject to a deductible. During 2024, we recorded $2.6 million of expense for our self-insured portion of these liabilities. We believe our recorded self-insurance reserves represent our best estimate of the outcomes of these claims. Should negative trends persist, we could be negatively impacted in the future.

Previous wording

Our failure to comply with immigration laws could result in significant liabilities, harm our reputation with our customers and disrupt our operations.

Current wording

If we fail to comply with immigration laws, such failure could result in significant liabilities, harm our reputation with our customers and disrupt our operations.

Previous wording

In addition, we face the threat to our computer systems of unauthorized access, computer hackers, computer viruses, malicious code, organized cyber-attacks and other security problems and system disruptions, including possible unauthorized access to and disclosure of our and our clients’ proprietary or classified information. We rely on industry accepted security measures and technology to securely maintain all confidential and proprietary information on our computer systems, but they may still be vulnerable to these threats. As a result, we may be required to expend significant

Current wording

unauthorized access to and disclosure of our and our clients’ proprietary or classified information. We rely on industry accepted security measures and technology to securely maintain all confidential and proprietary information on our computer systems, but they may still be vulnerable to these threats. As a result, we may be required to expend significant resources to protect against the threat of these system disruptions and security breaches or to alleviate problems caused by these disruptions and breaches. Any of these events could damage our reputation and have a material adverse effect on our business, financial condition, results of operations and cash flows.

Previous wording

At December 31, 2023, our total indebtedness under our three-year $103.0 million senior secured credit facility (the “Credit Agreement”), dated May 15, 2023, as amended, was approximately $38.0 million. We must comply with various affirmative and negative covenants contained in our Credit Agreement, some of which may restrict the way in which we would like to conduct our business. Among other things, our requirements under our debt instruments could potentially limit our ability to:

Current wording

At December 31, 2024, our total indebtedness under our three-year $103.0 million senior secured credit facility (the “Credit Agreement”), dated May 15, 2023, as amended, was approximately $23.0 million. We must comply with various affirmative and negative covenants contained in our Credit Agreement, some of which may restrict the way in which we would like to conduct our business. Among other things, our requirements under our debt instruments could potentially limit our ability to:

Previous wording

We may incur additional indebtedness in the future by issuing debt instruments, under new credit agreements, under joint venture credit agreements, under capital leases or synthetic leases, on a project-finance or other basis or a combination of these. If we incur additional indebtedness in the future, it likely would be under arrangements that may have terms and conditions at least as restrictive as those contained in our existing Credit Agreement. At December 31, 2023, available capacity to borrow on the revolving lines of credit was $47.7 million. Failure to comply with the terms and conditions of any existing or future indebtedness, including current or prospective covenants, would constitute an event of default. If an

Current wording

We may incur additional indebtedness in the future by issuing debt instruments, under new credit agreements, under joint venture credit agreements, under capital leases or synthetic leases, on a project-finance or other basis or a combination of these. If we incur additional indebtedness in the future, it likely would be under arrangements that may have terms and