QUANTA SERVICES, INC.

Previous wording

•Our business and operating results are subject to physical risks associated with climate change.

Current wording

•Our business and operating results are subject to physical risks associated with changes in climate.

Previous wording

•Increasing scrutiny and expectations with respect to corporate sustainability practices may impose additional costs on us or expose us to reputational or other risks.

Current wording

•Scrutiny and expectations with respect to corporate sustainability practices may impose additional costs on us or expose us to reputational or other risks.

Previous wording

Our business is dependent in part upon projects that can be cyclical in nature and are subject to risks of delay or cancellation. The timing of or failure to obtain contracts, delays in awards of, start dates for or completion of projects and the cancellations of projects can result in significant periodic fluctuations in our business, financial condition, results of operations and cash flows. Many of our projects involve challenging design, engineering, financing, permitting, right of way acquisition, procurement and construction phases that occur over extended time periods, sometimes several years, and we have encountered and may in the future encounter project delays, additional costs or project performance issues as a result of, among other things:

Current wording

Our business is dependent in part upon projects that can be cyclical in nature and are subject to risks of delay or cancellation. The timing of or failure to obtain contracts, delays in awards of, start dates for or completion of projects and the cancellations of projects can result in significant periodic fluctuations in our business, financial condition, results of operations and cash flows. Many of our projects involve complex design, engineering, financing, permitting, right of way acquisition, procurement and construction phases that occur over extended time periods, sometimes several years, and we have encountered and may in the future encounter project delays, additional costs or project performance issues as a result of, among other things:

Previous wording

•protests and other public activism, legal challenges or other political activity or opposition to a project;

Current wording

•protests and other public activism, legal challenges or other political activity or opposition to our operations or projects or those of our joint ventures;

Previous wording

We also generate a significant portion of our revenues under fixed price contracts, including contracts for large projects and/or projects where we provide EPC services (e.g., large electric transmission and substation projects and renewable generation projects). We have strategically expanded these service offerings in recent years, including with respect to renewable energy projects, and the size and scope of these projects continues to increase. The contracts for these projects often involve complex pricing, scope of services and other bid preparation components that require challenging estimates and assumptions on the part of our personnel, which increases the risk that costs incurred on such projects can vary, sometimes substantially, from our original estimates.

Current wording

We also generate a significant portion of our revenues under fixed price contracts, including contracts for large projects and/or projects where we provide EPC services (e.g., large electric transmission and substation projects, power generation projects, data center facility projects). We have strategically expanded these service offerings in recent years, including with respect to power generation projects, and the size and scope of these projects continues to increase. The contracts for these projects often involve complex pricing, scope of services and other bid preparation components that require challenging estimates and assumptions on the part of our personnel, which increases the risk that costs incurred on such projects can vary, sometimes substantially, from our original estimates.

Previous wording

In particular, locations throughout our primary operating regions, including but not limited to, the United States, Canada and Australia, have recently experienced and are increasingly impacted by wildfires, including locations that have not historically experienced wildfire events but that are becoming more susceptible to wildfire events due to changes in climate. Our customers operate electrical power, natural gas, communications and other infrastructure assets in these areas, which in turn has exposed us and other contractors to increased risk of liability in connection with our operations, as these wildfire events can be started by electrical power and other infrastructure on which we have performed services, including inspection, consulting, construction, upgrade, repair and maintenance and other services. For example, certain of our customers have been determined to be or are potentially responsible for certain catastrophic wildfire events in the western United States due to failure of their infrastructure, and certain of these wildfire events remain under investigation. Asdescribed further in Legal Proceedings - Silverado Wildfire Matter within Note 16 of the Notes to Consolidated Financial Statements in Item 8. Financial Statements and Supplementary Data in Part II of this Annual Report, two Quanta operating companies have received tenders of defense and demands for preservation of documents and indemnity in connection with a wildfire event, and additional claims or legal proceedings involving Quanta and its operating companies related to wildfire events may be brought in the future.

Current wording

In particular, locations throughout our primary operating regions, including but not limited to, the United States, Canada and Australia, have recently experienced and are increasingly impacted by wildfires, including locations that have not historically experienced wildfire events but that are becoming more susceptible to wildfire events due to changes in climate. Our customers operate electrical power, natural gas, communications and other infrastructure assets in these areas, which in turn has exposed us and other contractors to increased risk of liability in connection with our operations, as these wildfire events can be started by electrical power and other infrastructure on which we have performed services, including inspection, consulting, construction, upgrade, repair and maintenance and other services. For example, certain of our customers have been determined to be or are potentially responsible for certain catastrophic wildfire events in the western United States due to failure of their infrastructure, and certain of these wildfire events remain under investigation. From time to time, Quanta operating companies have received tenders of defense, demands for preservation of documents and indemnity and subpoenas during the course of investigations and reviews of wildfire events, which can often extend over a prolonged period of time, and additional claims or legal proceedings involving Quanta and its operating companies related to wildfire events may be brought in the future.

Previous wording

We also often perform services in locations that are densely populated and that have higher value property and assets, such as California and metropolitan areas, which can increase the impact of any of these hazards or other accidents. For example, one of our larger operating companies specializes in underground gas and electric distribution and transmission services and operates in metropolitan areas throughout the northeastern United States, including New York City, New York. Additionally, we operate a significant number of helicopters in the performance of our services, including the transportation of line workers, the setting of poles, the stringing of wires and wildfire control and prevention, among other activities, including in locations that have a higher risk of wildfires and in densely populated areas. Our operation of helicopters is subject to various risks, such as crashes, collisions, fires, adverse weather conditions or mechanical failures. We also perform site-work services and railroad construction services, as well as services on natural gas systems, pipelines, refineries, petrochemical plants and other infrastructure assets, and failure of or accidents with respect to work we perform on any of these types of assets could result in significant claims or liabilities. Additionally, we manufacture certain products, including power transformers and mobile energy storage systems, and a failure of one of our products could also lead to similar operational hazards (e.g., explosions or mechanical failures).

Current wording

We also often perform services in locations that are densely populated and that have higher value property and assets, such as California and metropolitan areas, which can increase the impact of any of these hazards or other accidents. For example, one of our larger operating companies specializes in underground gas and electric distribution and transmission services and operates in metropolitan areas throughout the northeastern United States, including New York City, New York. Additionally, we operate a significant number of helicopters in the performance of our services, including the transportation of line workers, the setting of poles, the stringing of wires and wildfire control and prevention, among other activities, including in locations that have a higher risk of wildfires and in densely populated areas. Our operation of helicopters is subject to various risks, such as crashes, collisions, fires, adverse weather conditions or mechanical failures. We also perform site-work services and railroad construction services, as well as services on natural gas systems, pipelines, refineries, petrochemical plants and other infrastructure assets, and failure of or accidents with respect to work we perform on any of these types of assets could result in significant claims or liabilities. We also manufacture certain products, including power transformers and mobile energy storage systems, and a failure of one of our products could also lead to similar operational hazards (e.g., explosions or mechanical failures).

Previous wording

Events arising from operational hazards and accidents have resulted in significant liabilities to us in the past and may expose us to significant claims and liabilities in the future. These claims and liabilities can arise through indemnification obligations to customers, our negligence or otherwise, and such claims and liabilities can arise even if our operations are not the cause of the harm. Our exposure to liability can also extend for years after we complete our services, and potential claims and liabilities arising from significant accidents and events can take years and significant legal costs to resolve.

Current wording

Events arising from operational hazards and accidents have resulted in significant liabilities to us in the past and may expose us to significant claims and liabilities in the future. These claims and liabilities can arise through indemnification obligations to customers, our negligence, negligence by our subcontractors or otherwise, and such claims and liabilities can arise even if our operations are not the cause of the harm. Our exposure to liability can also extend for years after we complete our services, and potential claims and liabilities arising from significant accidents and events can take years and significant legal costs to resolve.

Previous wording

Potential liabilities include, among other things, claims associated with personal injury, including severe injury or loss of life, and destruction of or significant damage to property and equipment (with respect to both our customers and other third parties), as well as harm to the environment, and other claims discussed above and can lead to suspension of operations, adverse effects to our safety record and reputation and/or material liabilities and legal costs. In addition, if any of these events or losses related thereto are alleged or found to be the result of our or our customer’s activities or services, we could be subject to government enforcement actions, regulatory penalties, civil litigation and governmental actions, including investigations, citations, fines and suspension of operations. Insurance coverage may not be available to us or may be insufficient to cover the cost of any of these liabilities and legal costs, and our insurance costs may increase if we incur liabilities associated with operational hazards. If we are not fully insured or indemnified against such liabilities and legal costs or a counterparty fails to meet its indemnification obligations to us, it could materially and adversely affect our business, financial condition, results of operations and cash flows. Further, to the extent our reputation or safety record is adversely affected, demand for our services could decline or we may not be able to bid for certain work.

Current wording

Potential liabilities include, among other things, claims associated with personal injury, including severe injury or loss of life, and destruction of or significant damage to property and equipment (with respect to both our customers and other third parties), as well as harm to the environment, and other claims discussed above and can lead to suspension of operations, adverse effects to our safety record and reputation and/or material liabilities and legal costs. In addition, if any of these events or losses related thereto are alleged or found to be the result of our or our customer’s activities or services, we could be subject to government enforcement actions, civil or criminal penalties, civil litigation and governmental actions, including investigations, citations, fines and suspension of operations. Insurance coverage may not be available to us or may be insufficient to cover the cost of any of these liabilities and legal costs, and our insurance costs may increase if we incur liabilities associated with operational hazards. If we are not fully insured or indemnified against such liabilities and legal costs or a counterparty fails to meet its indemnification obligations to us, it could materially and adversely affect our business, financial condition, results of operations and cash flows. Further, to the extent our reputation or safety record is adversely affected, demand for our services could decline or we may not be able to bid for certain work.

Previous wording

As part of our overall risk management strategy, we self-insure, or insure through our wholly-owned captive insurance company, a significant portion of our claims exposure, including all amounts up to the applicable deductible of our third-party insurance programs and certain additional amounts related to the general and auto liability programs. We are also responsible for our legal expenses relating to such claims, which can be significant both on an aggregate and individual claim basis. As a supplement to our self-insurance program, we maintain insurance with excess insurance carriers for potential losses, which exceed the amounts we self-insure or insure through our wholly-owned captive insurance company, arising out of our business and operations, and such insurance is subject to high deductibles. We renew our third-party insurance policies on an annual basis, and therefore deductibles and levels of coverage offered may change in future periods, and there is no assurance that any of our coverages will be renewed at their current levels or at all or that any future coverage will be available at reasonable and competitive rates. In connection with such renewals, we evaluate the level of insurance coverage and adjust insurance levels based on risk tolerance, risk volatility, and premium expense. Our insurance coverages may not be sufficient or effective under all circumstances or against all claims and liabilities asserted against us, and if we are not fully insured against such claims and liabilities, our business, financial condition. results of operations and cash flows could be materially and adversely affected. For example, due to the increased occurrence and future risk of wildfires, as described above, insurers have reduced coverage availability and increased the cost of insurance coverage for such events in recent years. As a result, Quanta’s current level of insurance coverage for wildfire events may not be sufficient to cover potential losses in connection with these events.

Current wording

As part of our overall risk management strategy, we self-insure, or insure through our wholly-owned captive insurance company, a significant portion of our claims exposure, including all amounts up to the applicable deductible of our third-party insurance programs and certain additional amounts related to the general and auto liability programs. We are also responsible for our legal expenses relating to such claims, which can be significant both on an aggregate and individual claim basis. As a supplement to our self-insurance program, we maintain insurance with excess insurance carriers for potential losses, which exceed the amounts we self-insure or insure through our wholly-owned captive insurance company, arising out of our business and operations, and such insurance is subject to high deductibles. We renew our third-party insurance policies on an annual basis, and therefore deductibles and levels of coverage offered may change in future periods, and there is no assurance that any of our coverages will be renewed at their current levels or at all or that any future coverage will be available at reasonable and competitive rates. In connection with such renewals, we evaluate the level of insurance coverage and adjust insurance levels based on risk tolerance, risk volatility, and premium expense. Our insurance coverages may not be sufficient or effective under all circumstances or against all claims and liabilities asserted against us, and if we are not fully insured against such claims and liabilities, our business, financial condition. results of operations and cash flows could be materially and adversely affected. For example, due to the increased occurrence and future risk of wildfires, as described above, insurers have reduced coverage availability and increased the cost of insurance coverage for such events in recent years. As a result, Quanta’s current level of insurance coverage for wildfire events may not be sufficient to cover potential losses in connection with these events. For more information see Risk Management and Insurancein Item 1. Businessin Part I of this Annual Report

Previous wording

Our business and operating results are subject to physical risks associated with climate change.

Current wording

Our business and operating results are subject to physical risks associated with changes in climate.

Previous wording

Changes in climate have caused, and are expected to continue to cause, among other things, increasing mean annual temperatures, rising sea levels and changes to meteorological and hydrological patterns, as well as impacts to the frequency and intensity of wildfires, hurricanes, floods, droughts, other storms and severe weather-related events and natural disasters. These changes have and could continue to significantly impact our future operating results and may have a long-term impact on our business, results of operation, financial condition and cash flows. While we seek to mitigate our risks associated with climate change, we recognize that there are inherent climate-related risks regardless of how and where we conduct our operations. For example, catastrophic natural disasters can negatively impact projects we are working on, our facilities and other physical locations, portions of our equipment, or the locations and service regions of our customers. Accordingly, a natural disaster has the potential to disrupt our and our customers’ businesses and may cause us to experience work stoppages, project delays, financial losses and additional costs to resume operations, including increased insurance costs or loss of coverage, legal liability and reputational losses, and we expect that increasing physical climate-related impacts may result in further changes to the cost or availability of insurance in the future.

Current wording

Changes in climate have caused, and are expected to continue to cause, among other things, changes to meteorological and hydrological patterns, as well as impacts to the frequency and intensity of wildfires, hurricanes, floods, droughts, extreme heat, other storms and severe weather-related events and natural disasters. These changes have and may in the future impact our future operating results and may have a long-term impact on our business, results of operation, financial condition and cash flows. While we seek to mitigate these risks, we recognize that certain risks are inherent given how and where we conduct our operations. For example, catastrophic natural disasters can negatively impact projects we are working on, our facilities and other physical locations, portions of our equipment, or the locations and service regions of our customers. Accordingly, a natural disaster has the potential to disrupt our and our customers’ businesses and may cause us to experience work stoppages, project delays, financial losses and additional costs to resume operations, including increased insurance costs or loss of coverage, legal liability and reputational losses, and we expect that increasing physical climate-related impacts may result in further changes to the cost or availability of insurance in the future.

Previous wording

Physical risks associated with climate change have also increased hazards associated with certain of our operations, which in turn has increased the potential for liability and increased the costs associated with such operations. For example, as discussed above, severe drought and high wind speeds have significantly increased the risk of wildfires throughout the areas where we operate, which in turn has exposed us and other contractors to increased risk of liability in connection with our operations in those locations, as these events can be started by electrical power and other infrastructure on which we have performed services. Given the potentially significant liabilities associated with these events, to the extent we are deemed liable for a wildfire event, it could have a material adverse impact on our business, financial condition, results of operations and cash flows. Furthermore, these climate conditions have also resulted in increased costs for wildfire-related third-party insurance and reduced the amount insurance carriers are willing to make available to us under such policies.

Current wording

Physical risks associated with changes in climate have also increased hazards associated with certain of our operations, which in turn has increased the potential for liability and increased the costs associated with such operations. For example, as discussed above, severe drought and high wind speeds have significantly increased the risk of wildfires throughout the areas where we operate, which in turn has exposed us and other contractors to increased risk of liability in connection with our operations in those locations, as these events can be started by electrical power and other infrastructure on which we have performed services. Given the potentially significant liabilities associated with these events, to the extent we are deemed liable for a wildfire event, it could have a material adverse impact on our business, financial condition, results of operations and cash flows. Furthermore, these climate conditions have also resulted in increased costs for wildfire-related third-party insurance and reduced the amount insurance carriers are willing to make available to us under such policies.

Previous wording

Our ability to efficiently manage our business and achieve our strategic initiatives is limited by our ability to employ, train and retain the necessary skilled personnel, which is subject to a number of risks. The demand for labor resources has continued to increase in response to the increasing duration and complexity of customer capital budgets, the commencement of new, large-scale infrastructure projects, increased demand for infrastructure improvements and reliability and increased pressure to reduce costs. The pool of skilled workers in certain of our industries has also been reduced, and may be further reduced, due primarily to an aging utility workforce and longer-term labor availability issues, including with respect to experienced program managers and qualified journeyman linemen available for our Electric Power segment and experienced supervisors and foremen for our Underground and Infrastructure segment. The cyclical nature of certain of the industries in which we operate can also create shortages of qualified labor during periods of high demand and production, and the amount of travel required for project management-level positions can impact the number of potential candidates that decide to enter our industries. A shortage in the supply of personnel creates competitive hiring markets that may result in increased labor expenses, and we have incurred, and expect to continue to incur, significant education and training expenses in order to recruit and train employees. The uncertainty of contract award timing and project delays can also present difficulties in managing our workforce size. Additionally, we may not be able to attract and retain the necessary skilled personnel for our expanding product and service offerings. Our inability to efficiently manage our workforce may require us to incur costs resulting from excess staff, reductions in staff, or redundancies that could have a material adverse impact on our business, financial condition, results of operations and cash flows.

Current wording

Our ability to efficiently manage our business and achieve our strategic initiatives is limited by our ability to employ, train and retain the necessary skilled personnel, which is subject to a number of risks. The demand for labor resources has continued to increase in response to the increasing duration and complexity of customer capital budgets, the commencement of new, large-scale infrastructure projects, increased demand for infrastructure improvements and reliability and increased pressure to reduce costs. The pool of skilled workers in certain of our industries has also been reduced, and may be further reduced, due primarily to an aging utility workforce and longer-term labor availability issues, including with respect to experienced program managers and qualified journeyman linemen available for our Electric segment and experienced supervisors and foremen for our Underground and Infrastructure segment. The cyclical nature of certain of the industries in which we operate can also create shortages of qualified labor during periods of high demand and production, and the amount of travel required for project management-level positions can impact the number of potential candidates that decide to enter our industries. A shortage in the supply of personnel creates competitive hiring markets that may result in increased labor expenses, and we have incurred, and expect to continue to incur, significant education and training expenses in order to recruit and train employees. The uncertainty of contract award timing and project delays can also present difficulties in managing our workforce size. Additionally, we may not be able to attract and retain the necessary skilled personnel for our expanding product and service offerings. Our inability to efficiently manage our workforce may require us to incur costs resulting from excess staff, reductions in staff, or redundancies that could have a material adverse impact on our business, financial condition, results of operations and cash flows.

Previous wording

Additionally, the recent inflationary pressure in the United States and our other markets has increased our labor costs. Under certain of our contracts, labor costs are passed through to customers, and the portion of our workforce that is represented by labor unions typically operates under multi-year collective bargaining agreements that provide some visibility into future labor costs. However, the costs related to a significant amount of our workforce are subject to market conditions, and therefore inflationary pressure could increase our labor costs with respect to those employees. Increased labor costs can also impact our customers’ decision-making with respect to viability or timing of certain projects, which could result in project delays or cancellations and in turn have a material adverse effect on our business, financial condition, results of operations or cash flows.

Current wording

Additionally, the inflationary pressure in the United States and our other markets has increased our labor costs. Under certain of our contracts, labor costs are passed through to customers, and the portion of our workforce that is represented by labor unions typically operates under multi-year collective bargaining agreements that provide some visibility into future labor costs. However, the costs related to a significant amount of our workforce are subject to market conditions, and therefore inflationary pressure could increase our labor costs with respect to those employees. Increased labor costs can also impact our customers’ decision-making with respect to viability or timing of certain projects, which could result in project delays or cancellations and in turn have a material adverse effect on our business, financial condition, results of operations or cash flows.

Previous wording

A few customers have in the past and may in the future account for a significant portion of our revenues. For example, our ten largest customers accounted for 31% of our consolidated revenues for the year ended December 31, 2024. Although we have long-standing relationships with many of our significant customers, a significant customer may unilaterally reduce or discontinue business with us at any time or merge or be acquired by a company that decides to reduce or discontinue business with us. A significant customer may also encounter financial constraints, based on cost of capital or other reasons, file for bankruptcy protection or cease operations, any of which could also result in reduced or discontinued business with us. The loss of business from a significant customer could have a material adverse effect on our business, financial condition, results of operations and cash flows.

Current wording

A few customers have in the past and may in the future account for a significant portion of our revenues. For example, our ten largest customers accounted for 30% of our consolidated revenues for the year ended December 31, 2025. Although we have long-standing relationships with many of our significant customers, a significant customer may unilaterally reduce or discontinue business with us at any time or merge or be acquired by a company that decides to reduce or discontinue business with us. A significant customer may also encounter financial constraints, based on cost of capital or other reasons, file for bankruptcy protection or cease operations, any of which could also result in reduced or discontinued business with us. The loss of business from a significant customer could have a material adverse effect on our business, financial condition, results of operations and cash flows.

Previous wording

Note 4 of the Notes to Consolidated Financial Statements in Item 8. Financial Statements and Supplementary Data in Part II of this Annual Report. These types of claims occur due to, among other things, impacts to projects as a result of factors not within the control of Quanta, such as natural disasters, significant weather events and public health events (e.g., pandemics), delays caused by customers and third parties and changes in project scope, which can result in additional costs that may not be recovered until the claim is resolved. While we generally negotiate with the customer for additional compensation, we may be unable to obtain, through negotiation, arbitration, litigation or otherwise, adequate amounts to compensate us for the additional work or expenses incurred. Litigation, arbitration or government approval (if needed) with respect to these matters is generally lengthy and costly, involves significant uncertainty as to timing and amount of any resolution, and can adversely affect our relationship with existing or potential customers. Furthermore, we can be required to invest significant working capital to fund cost overruns while the resolution of a claim is pending. Failure to obtain adequate and prompt compensation for these matters can result in a reduction of revenues and gross profit recognized in prior periods or the recognition of a loss. Any such reduction or loss can be substantial and can have a material adverse effect on our business, financial condition, results of operations and cash flows.

Current wording

We have in the past brought, and may in the future bring, claims against our customers. For example, as of December 31, 2025, the amount recognized related to unapproved change orders and claims was $983.6 million, which is discussed further in Note 4 of the Notes to Consolidated Financial Statements in Item 8. Financial Statements and Supplementary Data in Part II of this Annual Report. These types of claims occur due to, among other things, impacts to projects as a result of factors not within the control of Quanta, such as natural disasters, significant weather events and public health events (e.g., pandemics), delays caused by customers and third parties and changes in project scope, which can result in additional costs that may not be recovered until the claim is resolved. While we generally negotiate with the customer for additional compensation, we may be unable to obtain, through negotiation, arbitration, litigation or otherwise, adequate amounts to compensate us for the additional work or expenses incurred. Litigation, arbitration or government approval (if needed) with respect to these matters is generally lengthy and costly, involves significant uncertainty as to timing and amount of any resolution, and can adversely affect our relationship with existing or potential customers. Furthermore, we can be required to invest significant working capital to fund cost overruns while the resolution of a claim is pending. Failure to obtain adequate and prompt compensation for these matters can result in a reduction of revenues and gross profit recognized in prior periods or the recognition of a loss. Any such reduction or loss can be substantial and can have a material adverse effect on our business, financial condition, results of operations and cash flows.

Previous wording

We have in the past been, and may in the future be, named as a defendant in lawsuits, claims and other legal proceedings that arise in the ordinary course of our business. These actions seek, among other things, compensation for alleged personal injury (including claims for loss of life), workers’ compensation, employment discrimination, sexual harassment, workplace misconduct, wage and hour claims and other employment-related damages, compensation for breach of contract, negligence or gross negligence or property damage, environmental liabilities, multiemployer pension plan withdrawal liabilities, punitive damages, consequential damages, and civil penalties or other losses or injunctive or declaratory relief, as well as interest and attorneys’ fees associated with such claims. Furthermore, given our recent growth, we have become a more attractive target for lawsuits by various third parties.

Current wording

We have in the past been, and may in the future be, named as a defendant in lawsuits, claims and other legal proceedings that arise in the ordinary course of our business. These actions seek, among other things, compensation for alleged personal injury (including claims for loss of life), workers’ compensation, employment discrimination, sexual harassment, workplace misconduct, wage and hour claims and other employment-related damages, compensation for breach of contract, negligence or gross negligence or property damage, environmental liabilities, multiemployer pension plan withdrawal liabilities, punitive damages, consequential damages, and civil penalties or other losses or injunctive or declaratory relief, as well as interest and attorneys’ fees associated with such claims. Furthermore, given the growth that we have experienced, we have become a more attractive target for lawsuits by various third parties.

Previous wording

In addition, many customers, particularly in connection with new construction, require us to post performance and payment bonds. These bonds provide a guarantee that we will perform under the terms of a contract and pay our subcontractors and vendors. If we fail to perform, the customer may demand that the surety make payments or provide services under the bond, and we must reimburse the surety for any expenses or outlays it incurs. As of December 31, 2024, the total amount of our outstanding performance bonds was estimated to be approximately $9.5 billion. To the extent reimbursements are required, the amounts could be material and could adversely affect our consolidated business, financial condition, results of operations or cash flows.

Current wording

In addition, many customers, particularly in connection with new construction, require us to post performance and payment bonds. These bonds provide a guarantee that we will perform under the terms of a contract and pay our subcontractors and vendors. If we fail to perform, the customer may demand that the surety make payments or provide services under the bond, and we must reimburse the surety for any expenses or outlays it incurs. As of December 31, 2025, the total amount of our outstanding performance bonds was estimated to be approximately $14.9 billion. To the extent reimbursements are required, the amounts could be material and could adversely affect our consolidated business, financial condition, results of operations or cash flows.

Previous wording

Furthermore, our business involves professional judgments regarding the planning, design, development, construction, operations and management of electric power, renewable generation, communications, underground utility and pipeline infrastructure. Because our projects are often technically complex, our failure to make judgments and recommendations in accordance with applicable professional standards, including engineering standards, could result in damages. A significantly adverse or catastrophic event at a project site or completed project resulting from the services we performed could result in significant professional or product liability, personal injury (including claims for loss of life) or property damage claims or other claims against us, as well as reputational harm. These liabilities could exceed our insurance limits or impact our ability to obtain third-party insurance in the future, and customers, subcontractors or suppliers who have agreed to indemnify us against any such liabilities or losses might refuse or be unable to pay us. As a result, warranty, engineering and other related claims could have a material adverse impact on our business, financial condition, results of operations and cash flows.

Current wording

Furthermore, our business involves professional judgments regarding the planning, design, development, construction, operations and management of electric power, power generation, communications, underground utility, pipeline and other infrastructure. Because our projects are often technically complex, our failure to make judgments and recommendations in accordance with applicable professional standards, including engineering standards, could result in damages. A significantly adverse or catastrophic event at a project site or completed project resulting from the services we performed could result in significant professional or product liability, personal injury (including claims for loss of life) or property damage claims or other claims against us, as well as reputational harm. These liabilities could exceed our insurance limits or impact our ability to obtain third-party insurance in the future, and customers, subcontractors or suppliers who have agreed to indemnify us against any such liabilities or losses might refuse or be unable to pay us. As a result, warranty, engineering and other related claims could have a material adverse impact on our business, financial condition, results of operations and cash flows.

Previous wording

We rely on information technology systems to manage our operations and other business processes and to protect sensitive company information. We also collect and retain information about our customers, stockholders, vendors, employees, contractors, business partners and other parties, all of whom expect that we will adequately protect such information. We face numerous and evolving cybersecurity risks that threaten the confidentiality, integrity and availability of our information technology systems and confidential information as well as the systems and information of key third parties and information technology vendors upon whom we rely. Certain of our vendors have experienced cyber-attacks that exploited vulnerabilities in their systems and have resulted in disruptions to their systems. While these events have not resulted in any known material impacts to our systems, we expect such attacks will continue in the future. Furthermore, the energy infrastructure systems on which we work are strategic targets that are at greater risk of cyber-attacks or acts of terrorism than other targets. Additionally, an intrusion into the information systems of a business we acquire may also ultimately compromise our systems. Our operations are decentralized with operating companies maintaining some of their own information systems, data and service providers. While our cybersecurity risk management program and processes, including policies, controls and procedures, are designed to cover our operating companies, there can be no assurance that these will be fully implemented, complied with or effective in protecting all information systems and operations.

Current wording

We rely on information technology systems to manage our operations and other business processes and to protect sensitive company information. We also collect and retain information about our customers, stockholders, vendors, employees, contractors, business partners and other parties, all of whom expect that we will adequately protect such information. We face numerous and evolving cybersecurity risks that threaten the confidentiality, integrity and availability of our information technology systems and confidential information as well as the systems and information of key third parties and information technology vendors upon whom we rely. Certain of our vendors have experienced cyber-attacks that exploited vulnerabilities in their systems and have resulted in disruptions to their systems. While these events have not resulted in any known material impacts to our systems, we expect such attacks will continue in the future. Furthermore, the infrastructure systems and facilities on which we work are strategic targets that are at greater risk of cyber-attacks or acts of terrorism than other targets. Additionally, an intrusion into the information systems of a business we acquire may also ultimately compromise our systems. Our operations are decentralized with operating companies maintaining some of their own information systems, data and service providers, including some of their own security controls and processes. There can be no assurance that our cybersecurity risk management program and processes, including policies, controls and procedures, designed to apply to our operating companies will be fully implemented, complied with or effective in protecting all information systems and operations.

Previous wording

While we have security measures and technology in place to protect our and our clients’ confidential or proprietary company information, there can be no assurance that our efforts will prevent all threats to our systems and information. Moreover, we have acquired and continue to acquire companies with cybersecurity vulnerabilities and/or unsophisticated security measures, which exposes us to significant cybersecurity, operational, and financial risks until they are fully integrated into our information systems. Additionally, the increased use of remote working arrangements by employees, vendors, and other third parties has increased the exposure to possible attacks, thereby increasing the risk of a data security compromise.

Current wording

Our security measures and technology to protect our and our clients’ confidential or proprietary company information may not be successful, and there can be no assurance that our efforts will prevent all threats to our systems and information. Moreover, we have acquired and continue to acquire companies with cybersecurity vulnerabilities and/or unsophisticated security measures, which exposes us to significant cybersecurity, operational, and financial risks until they are fully integrated into our information systems. Additionally, the increased use of remote working arrangements by employees, vendors, and other third parties has increased the exposure to possible attacks, thereby increasing the risk of a data security compromise.

Previous wording

We have experienced and addressed cyber-attacks, breaches and disruptions of our information systems, and systems of key third parties and information technology vendors that we rely upon, in the past, and we expect such events to continue to arise in the future. While to date we have not experienced any material impact as a result of these events, the ultimate impact of future and similar events remains unknown, and we expect additional vulnerabilities to arise. Cyber-attacks can result in compromises of our payment systems, monetary losses, inability to access or operate our systems (e.g., ransomware), delays in processing transactions or reporting financial results, the disclosure or misappropriation of confidential, personal or proprietary company information (including for the purpose of transacting in our stock), or the release of customer, stockholder, vendor or employee information. An attack could also cause material service disruptions to our internal systems or, in extreme circumstances, infiltration into, damage to or loss of control of our customers’ energy infrastructure systems. Any such breach or disruption could subject us to material liabilities, cause damage to our reputation or customer relationships, or result in regulatory investigations or other actions by governmental authorities, which could have a material adverse impact on our business, financial condition, results of operations and cash flows. Furthermore, we may incur additional costs related to the investigation and reporting of any such breach or disruption. Additionally, because the techniques used to obtain unauthorized access or sabotage information technology systems change frequently and are generally not identifiable until they are launched against a target, we are unable to anticipate all attacker techniques or to implement comprehensive preventative measures, particularly because threat actors are increasingly using tools, including artificial intelligence, that are designed to circumvent controls and evade detection. As a result, we may be required to expend significant resources to protect against the threat of system disruptions and security breaches or to alleviate problems caused by these disruptions and breaches.

Current wording

We have experienced and addressed cyber-attacks, breaches and disruptions of our information systems, and systems of key third parties and information technology vendors that we rely upon, in the past, and we expect such events to continue to arise in the future. While to date we have not experienced any material impact as a result of these events, the ultimate impact of future and similar events remains unknown, and we expect additional vulnerabilities to arise. Cyber-attacks can result in compromises of our payment systems, monetary losses, inability to access or operate our systems (e.g., ransomware), delays in processing transactions or reporting financial results, the disclosure or misappropriation of confidential, personal or proprietary company information (including for the purpose of transacting in our stock), or the release of customer, stockholder, vendor or employee information. An attack could also cause material service disruptions to our internal systems or to our operating companies’ systems, or in extreme circumstances, infiltration into, damage to or loss of control of our customers’ energy infrastructure systems. Any such breach or disruption could subject us to material liabilities, cause damage to our reputation or customer relationships, or result in regulatory investigations or other actions by governmental authorities as well as litigation, which could have a material adverse impact on our business, financial condition, results of operations and cash flows. Furthermore, we may incur substantial costs related to the investigation and reporting of any such breach or disruption. Additionally, because the techniques used to obtain unauthorized access or sabotage information technology systems change frequently and are generally not identifiable until they are launched against a target, we are unable to anticipate all attacker techniques or to implement comprehensive preventative measures, particularly because threat actors are increasingly using tools, including artificial intelligence, that are designed to circumvent controls and evade detection. As a result, we may be required to expend significant resources to protect against the threat of system disruptions and security breaches or to alleviate problems caused by these disruptions and breaches.

Previous wording

In addition, as a contractor supporting government agencies with respect to certain projects, including the Department of Defense (DoD), we must adhere to regulatory cyber compliance requirements outlined in the Federal Acquisition Regulations (FAR), the Defense Federal Acquisition Regulation Supplement (DFARS), and other federal mandates with respect to these projects. The DoD is also in the process of implementing obligations relating to the Cyber Security Material Model Certificate (CMMC) into its contracts. The DoD expects that new contracts will be required to comply with the CMMC by 2026. In addition, any obligations that may be imposed on us under the CMMC may be different from or in addition to those otherwise required by applicable laws and regulations, which may cause additional expense for compliance. Failure to meet these various requirements, whether mandated by regulation or contract, could cause material harm to our business, financial condition and reputation.

Current wording

In addition, as a contractor supporting government agencies with respect to certain projects, including the Department of Defense (DoD), we must adhere to regulatory cyber compliance requirements outlined in the Federal Acquisition Regulations (FAR), the Defense Federal Acquisition Regulation Supplement (DFARS), and other federal mandates with respect to these projects. The DoD has also finalized the Cybersecurity Maturity Model Certification (CMMC) process and commenced in late 2025 the process of incorporating CMMC assessments in applicable procurements. Obligations that may be imposed on us under the CMMC may be different from or in addition to those otherwise required by applicable laws and regulations, which may cause additional expense for compliance. Failure to meet these various requirements, whether mandated by regulation or contract, could cause material harm to our business, financial condition and reputation.

Previous wording

•failure to successfully perform, or negative publicity related to, a high-profile project, including, among others, our joint venture in LUMA and large-scale infrastructure projects designed to support the energy transition (i.e., large electric transmission and renewable generation projects) and technological advancements (e.g., data center facilities);

Current wording

•failure to successfully perform, or negative publicity related to, a high-profile project, including, among others, our joint venture in LUMA and large-scale infrastructure projects (i.e., electric transmission projects, renewable and other generation projects and data center and manufacturing facilities);

Previous wording

•actual or potential involvement in a catastrophic fire, explosion, mechanical failure of infrastructure or similar event; or

Current wording

•actual or potential involvement in a catastrophic fire, explosion, aviation incident, mechanical failure of infrastructure or similar event; or

Previous wording

Our results of operations and financial condition can also be adversely affected by impairments to goodwill, other intangible assets, and long-lived assets, the value of which is dependent upon certain estimates and assumptions. We record goodwill when we acquire a business, which must be tested at least annually for impairment. We have recorded impairments in the past, and any future impairments could have a material adverse effect on our financial condition and results of operations for the period in which the impairment is recognized. See Critical Accounting Estimates in Item 7. Management’s Discussion and Analysis of Financial Conditionin Part II of this Annual Report for further information about our critical accounting estimates.

Current wording

Our results of operations and financial condition can also be adversely affected by impairments to goodwill, other intangible assets, and long-lived assets, the value of which is dependent upon certain estimates and assumptions. We record goodwill when we acquire a business, which must be tested at least annually for impairment. We have recorded impairments in the past, and any future impairments could have a material adverse effect on our financial condition and results of operations for the period in which the impairment is recognized. See Critical Accounting Estimates in Item 7. Management’s Discussion and Analysis of Financial Condition in Part II of this Annual Report for further information about our critical accounting estimates.

Previous wording

Additionally, we also generally require that key management and former principals of the businesses we acquire agree to non-compete covenants in the purchase agreement or, as applicable, employment agreements. Enforceability of these non-competition agreements varies by jurisdiction and typically is dependent upon specific facts and circumstances, making it difficult to predict their enforceability. Additionally, the FTC has adopted new rules to, among other things, prohibit and make unenforceable any post-employment non-compete arrangement that restricts an employee or individual independent contractor, unless such arrangement was entered into in connection with an acquisition and meets certain conditions. While these rules have been challenged judicially and their implementation has been stayed, if the rules are ultimately upheld, we might be subject to increased competition if the restrictive covenants entered into by key management personnel of acquired businesses are not enforceable or have expired, which could materially and adversely affect our business, financial condition, results of operations and cash flows.

Current wording

Additionally, we also generally require that key management and former principals of the businesses we acquire agree to non-compete covenants in the purchase agreement or, as applicable, employment agreements. Enforceability of these non-competition agreements varies by jurisdiction and typically is dependent upon specific facts and circumstances, making it difficult to predict their enforceability. Therefore, if a member of the key management of the business we acquire is terminated, we might be subject to increased competition if the restrictive covenants entered into by such person are not enforceable or have expired, which could materially and adversely affect our business, financial condition, results of operations and cash flows.

Previous wording

We depend on the continued efforts of our executive officers, senior corporate management, regional leadership and management of our operating companies, which includes leadership and key personnel of the businesses we acquire. Although we typically enter into employment agreements with our executive officers and other key employees for initial terms of one year and subsequent renewal options, we cannot be certain that any individual will continue in such capacity for any particular period of time. We also depend on our ability to attract key operational and professional personnel as we grow our business and in order to establish and maintain an effective succession planning process. A shortage of these employees for various reasons, including intense competition for skilled employees, labor shortages, increased labor costs and the preference of some candidates to work remotely, could jeopardize our ability to successfully manage our decentralized operations or our ability to grow and expand our business. As a result, the loss of key personnel, as well as our inability to attract, develop and retain qualified employees that can succeed these key personnel, could negatively impact our ability to manage our business. Additionally, if the FTC rules regarding non-compete covenants discussed above are upheld and ultimately implemented, Quanta could be required to individually rescind any post-termination non-compete clauses in its employment and other service agreements with key management, other employees and individual independent contractors, which would increase the risk that key individuals, upon departure from Quanta, would compete with us despite any severance or other consideration paid or owed to any such individual.

Current wording

We depend on the continued efforts of our executive officers, senior corporate management, regional leadership and management of our operating companies, which includes leadership and key personnel of the businesses we acquire. Although we typically enter into employment agreements with our executive officers and other key employees for initial terms of one year and subsequent renewal options, we cannot be certain that any individual will continue in such capacity for any particular period of time. We also depend on our ability to attract key operational and professional personnel as we grow our business and in order to establish and maintain an effective succession planning process. A shortage of these employees for various reasons, including intense competition for skilled employees, labor shortages, increased labor costs and the preference of some candidates to work remotely, could jeopardize our ability to successfully manage our decentralized operations or our ability to grow and expand our business. As a result, the loss of key personnel, as well as our inability to attract, develop and retain qualified employees that can succeed these key personnel, could negatively impact our ability to manage our business.

Previous wording

We have entered into strategic relationships, joint ventures and other investment arrangements with various partners, including customers and infrastructure investors, through which we have invested in infrastructure assets and businesses, and we expect this activity to continue in the future. Certain of these investments are described further in Note 8 of the Notes to Consolidated Financial Statements in Item 8. Financial Statements and Supplementary Data in Part II of this Annual Report. These types of investments expose us to increased risks, including poor performance by the infrastructure projects or businesses in which we have invested due to, among other things, difficult market or economic conditions or slowdowns (which may occur across one or more industries, sectors or geographies), changes to the supply or demand and fluctuations in the price of commodities, or fluctuations in the market price of the equity securities we hold in a company. That negative performance could result in lower investment returns, a decline in value or total loss of our investments or the possible sale of our investments at values below our initial projections, including at a loss, all of which could adversely affect our business, financial condition, results of operations and cash flows. For example, during 2022, we recorded a $91.5 million impairment in connection with our investment in Starry Group Holdings, Inc. Furthermore, our investments are often illiquid, as they are typically investments in private companies and/or subject to contractual restrictions that impose restrictions or lock-up periods affecting our ability to sell our interest, and as a result, we may not be able to exit an investment that is performing poorly, declining in value or resulting in reputational harm. Quanta may also be exposed to reputational harm based on poor or incomplete performance of our investments or an investment fund in which we participate, or based on the actions or conduct of the entities in which we are invested or our partners in such investments, all of which may be outside of our control. Any such reputational harm could adversely affect our ability to secure certain future projects or participate in future investment opportunities. Further, our relationship with a customer or investor that partners with us in a poorly performing investment could become impaired, which may negatively impact our ability to continue providing services to that customer.

Current wording

We have entered into strategic relationships, joint ventures and other investment arrangements with various partners, including customers and infrastructure investors, through which we have invested in infrastructure assets and businesses, and we expect this activity to continue in the future. Certain of these investments are described further in Note 8 of the Notes to Consolidated Financial Statements in Item 8. Financial Statements and Supplementary Data in Part II of this Annual Report. These types of investments expose us to increased risks, including poor performance by the infrastructure projects or businesses in which we have invested due to, among other things, difficult market or economic conditions or slowdowns (which may occur across one or more industries, sectors or geographies), changes to the supply or demand and fluctuations in the price of commodities, or fluctuations in the market price of the equity securities we hold in a company. That negative performance could result in lower investment returns, a decline in value or total loss of our investments or the possible sale of our investments at values below our initial projections, including at a loss, all of which could adversely affect our business, financial condition, results of operations and cash flows. Furthermore, our investments are often illiquid, as they are typically investments in private companies and/or subject to contractual restrictions that impose restrictions or lock-up periods affecting our ability to sell our interest, and as a result, we may not be able to exit an investment that is performing poorly, declining in value or resulting in reputational harm. Quanta may also be exposed to reputational harm based on poor or incomplete performance of our investments or an investment fund in which we participate, or based on the actions or conduct of the entities in which we are invested or our partners in such investments, all of which may be outside of our control. Any such reputational harm could adversely affect our ability to secure certain future projects or participate in future investment opportunities. Further, our relationship with a customer or investor that partners with us in a poorly performing investment could become impaired, which may negatively impact our ability to continue providing services to that customer.

Previous wording

Our overall business, financial condition, results of operations and cash flows can be negatively impacted by our activities and operations outside the continental United States, including our international operations and operations in U.S. territories. Although these operations are presently conducted primarily in Canada and Australia, we also perform work in other foreign countries and U.S. territories. For the year ended December 31, 2024, we derived $2.07 billion, or 8.7%, of our consolidated revenues from foreign operations, the substantial majority of which was related to Canada and Australia. Changes in economic conditions, including those resulting from wars and other geopolitical conflicts, civil unrest, public health crises, pandemics, acts of terrorism, or volatility in global markets, may adversely affect demand for our services and our customers’ ability to pay for our services. In addition, at times we are paid for work outside the United States in currencies other than the U.S. dollar. Such payments are subject to fluctuating foreign currency exchange rates and may exceed our local currency needs, and, in certain instances, those amounts may be subject to temporary blocking, taxes or tariffs, and we may experience difficulties if we attempt to convert such amounts to U.S. dollars. Furthermore, to the extent the volume of services we provide internationally increases, our financial condition, results of operations and cash flows could be further exposed to the effects of fluctuating exchange rates.

Current wording

Our overall business, financial condition, results of operations and cash flows can be negatively impacted by our activities and operations outside the continental United States, including our international operations and operations in U.S. territories. Although these operations are presently conducted primarily in Canada and Australia, we also perform work in other foreign countries and U.S. territories. For the year ended December 31, 2025, we derived $2.00 billion, or 7.0%, of our consolidated revenues from foreign operations, the substantial majority of which was related to Canada and Australia. Changes in economic conditions, including those resulting from wars and other geopolitical conflicts, civil unrest, public health crises, pandemics, acts of terrorism, or volatility in global markets, may adversely affect demand for our services and our customers’ ability to pay for our services. In addition, at times we are paid for work outside the United States in currencies other than the U.S. dollar. Such payments are subject to fluctuating foreign currency exchange rates and may exceed our local currency needs, and, in certain instances, those amounts may be subject to temporary blocking, taxes or tariffs, and we may experience difficulties if we attempt to convert such amounts to U.S. dollars. Furthermore, to the extent the volume of services we provide internationally increases, our financial condition, results of operations and cash flows could be further exposed to the effects of fluctuating exchange rates.

Previous wording

There are numerous other risks associated with operating in international markets and U.S. territories, including, but not limited to, changes in applicable regulatory requirements; political, economic and social instability; expropriation or nationalization of our assets and operations; unfamiliar legal systems or business and labor practices; and complex U.S. and foreign tax regulations and other laws and international treaties. For example, our joint venture, LUMA, is exposed to various risks operating in Puerto Rico. Furthermore, we have incurred, and may incur in the future, significant costs or liabilities associated with an unsuccessful attempt to enter a new market and we have entered, and may in the future enter, a new market that ultimately proves to be unprofitable or has an otherwise adverse effect on our business. We may also incur significant costs and liabilities associated with winding down or exiting an existing market. These risks could restrict our ability to provide services to customers, operate our business in these locations profitably or fund our strategic objectives, which could negatively impact our overall business, financial condition, results of operations and cash flows.

Current wording

Furthermore, we have incurred, and may incur in the future, significant costs or liabilities associated with an unsuccessful attempt to enter a new market and we have entered, and may in the future enter, a new market that ultimately proves to be unprofitable or has an otherwise adverse effect on our business. We may also incur significant costs and liabilities associated with winding down or exiting an existing market. These risks could restrict our ability to provide services to customers, operate our business in these locations profitably or fund our strategic objectives, which could negatively impact our overall business, financial condition, results of operations and cash flows.

Previous wording

Additionally, successful completion of our contracts can depend on whether our subcontractors successfully fulfill their contractual obligations. If our subcontractors fail to perform their contractual obligations, fail to meet the expected completion dates or quality or safety standards or fail to comply with applicable laws, such shortcomings may subject us to claims or we may be required to incur additional costs or provide additional services to mitigate such shortcomings. As a result, regulatory or other requirements that require us to outsource a percentage of services to subcontractors, whether they are businesses meeting diversity-ownership requirements or otherwise, also limit our ability to self-perform our services, thereby potentially increasing performance risk associated with our services. Furthermore, services subcontracted to other service providers generally yield lower margins, and therefore these regulatory requirements can impact our profitability and results of operations.

Current wording

Additionally, successful completion of our contracts can depend on whether our subcontractors successfully fulfill their contractual obligations. If our subcontractors fail to perform their contractual obligations, fail to meet the expected completion dates or quality or safety standards or fail to comply with applicable laws, such shortcomings may subject us to claims or liabilities, including from customers and third parties, or we may be required to incur additional costs or provide additional services to mitigate such shortcomings. As a result, regulatory or other requirements that require us to outsource a percentage of services to subcontractors, whether they are businesses meeting diversity-ownership requirements or otherwise, also limit our ability to self-perform our services, thereby potentially increasing performance risk associated with our services. Furthermore, services subcontracted to other service providers generally yield lower margins, and therefore these regulatory requirements can impact our profitability and results of operations.

Previous wording

Pursuant to certain contracts, including fixed price and EPC contracts where we have assumed responsibility for procuring materials for a project, we are exposed to availability issues and price increases for materials that are utilized in connection with our operations, including, among other things, copper, steel, aluminum, specialized project components (e.g., transformers, solar panels) and raw materials utilized for certain of our product solutions. In addition, the timing of our customers’ ongoing projects, as well as their capital budgets and decision-making with respect to the timing of the future projects, can be negatively impacted by a lack of availability or an increase in prices of these materials. Prices and availability could be materially impacted by, among other things, supply chain and other logistical challenges (including inability of manufacturers to timely meet demand), global trade relationships (e.g., tariffs, duties, taxes, assessments, sourcing restrictions) and other general market and geopolitical conditions (e.g., inflation, market volatility, increased interest rates and geopolitical conflicts). The lack of availability of necessary materials could result in project delays, some of which could be attributable to us, and an increase in prices of materials could reduce our profitability on projects or negatively impact our customers, which could have an adverse effect on demand for our services or our business, financial condition, results of operations and cash flows. For example, in the past sourcing restrictions on critical components for our customers’ projects (e.g., solar panels) have resulted in supply chain and logistical challenges, which negatively impacted certain of our services. We may continue to be impacted by sourcing restrictions, including, but not limited to, taxes. tariffs and duties, which may negatively impact project timing within certain of our markets in the future. Additionally, the availability of power transformers utilized in electric power projects has been negatively impacted by the inability of manufacturers to meet current market demand, which has increased, and is expected to continue to increase.

Current wording

Pursuant to certain contracts, including fixed price and EPC contracts where we have assumed responsibility for procuring materials for a project, we may be exposed to availability issues and price increases for materials that are utilized in connection with our operations, including, among other things, copper, steel, aluminum, specialized project components (e.g., transformers, solar panels, breakers, turbines, batteries) and raw materials utilized for certain of our product solutions. In addition, the timing of our customers’ ongoing projects, as well as their capital budgets and decision-making with respect to the timing of the future projects, can be negatively impacted by a lack of availability or an increase in prices of these materials. Prices and availability could be materially impacted by, among other things, supply chain and other logistical challenges (including inability of manufacturers to timely meet demand), global trade relationships (e.g., tariffs, duties, taxes, assessments, sourcing restrictions) and other general market and geopolitical conditions (e.g., inflation, market volatility, increased interest rates and geopolitical conflicts). The lack of availability of necessary materials could result in project delays, some of which could be attributable to us, and an increase in prices of materials could reduce our profitability on projects or negatively impact our customers, which could have an adverse effect on demand for our services or our business, financial condition, results of operations and cash flows. For example, in the past sourcing restrictions on critical components for our customers’ projects (e.g., solar panels) have resulted in supply chain and logistical challenges, which negatively impacted certain of our services. We may continue to be impacted by sourcing restrictions, including, but not limited to, taxes, tariffs and duties, which may negatively impact project timing within certain of our markets in the future. Additionally, the availability of power transformers utilized in electric power projects has been negatively impacted by the inability of manufacturers to meet current market demand, which has increased, and is expected to continue to increase.

Previous wording

We are also exposed to increases in energy prices, particularly fuel prices for our large fleet of vehicles, which have fluctuated significantly since 2020 and could increase over the longer term due to market conditions or future regulatory, legislative and policy changes. Furthermore, some of our fixed price contracts do not allow us to adjust our prices and certain of our other contracts, such as some long-term MSAs, allow for price adjustments within a certain range that may be insufficient for us to recover the full amount associated with increased fuel costs. As a result, increases in fuel costs could reduce our profitability with respect to such projects. Our ability to utilize certain existing vehicles within our fleet may also be limited by new emissions or other regulations, and, due to lack of production or availability, we may not be able to procure a sufficient number of vehicles meeting any such regulations. To the extent we are unable to utilize a significant portion of our existing fleet, we may be unable to perform services, which could have an adverse effect on our future financial condition, results of operations and cash flows. Additionally, to the extent we are required to transition our fleet to alternative sources of power, including EVs, and the availability of such vehicles is limited or fluctuates, we may be unable to efficiently plan for such transition, which could result in, among other things, the retirement of certain vehicles prior to the end of their useful life. The broader and longer-term implications of these challenges, which could accelerate, remain highly uncertain and variable and could negatively impact our overall business, financial condition, results of operations and cash flows.

Current wording

We are also exposed to increases in energy prices, particularly fuel prices for our large fleet of vehicles, which have fluctuated significantly since 2020 and could increase over the longer term due to market conditions or future regulatory, legislative and policy changes. Furthermore, some of our fixed price contracts do not allow us to adjust our prices and certain of our other contracts, such as some long-term MSAs, allow for price adjustments within a certain range that may be insufficient for us to recover the full amount associated with increased fuel costs. As a result, increases in fuel costs could reduce our profitability with respect to such projects. Our ability to utilize certain existing vehicles within our fleet may also be limited by new emissions or other regulations, and, due to lack of production or availability, we may not be able to procure a sufficient number of vehicles meeting any such regulations. To the extent we are unable to utilize a significant portion of our existing fleet, we may be unable to perform services, which could have an adverse effect on our future financial condition, results of operations and cash flows. The broader and longer-term implications of these challenges remain highly uncertain and variable and could negatively impact our overall business, financial condition, results of operations and cash flows.

Previous wording

Increasing scrutiny and changing expectations from various stakeholders with respect to corporate sustainability practices may impose additional costs on us or expose us to reputational or other risks.

Current wording

Scrutiny and expectations from various stakeholders with respect to corporate sustainability practices may impose additional costs on us or expose us to reputational or other risks.

Previous wording

Investors, customers and other stakeholders have focused increasingly on sustainability practices of companies, including, among other things, practices with respect to human capital resources, emissions and environmental impact and political spending. Expectations and requirements of our investors, customers and other third parties evolve rapidly and are largely out of our control, and our initiatives and disclosures in response to such expectations and requirements may result in increased costs (including but not limited to increased costs related to compliance, stakeholder engagement, contracting and insurance), changes in demand for certain services, enhanced compliance or disclosure obligations, or other adverse impacts to our business, financial condition, or results of operations. While we have programs and initiatives in place related to our sustainability practices, investors may decide to reallocate capital or to not commit capital as a result of their assessment of our practices. In addition, our customers may require that we implement certain additional procedures or standards in order to continue to do business with us. A failure to comply with investor, customer and other stakeholder expectations and standards, which are evolving and can conflict, or if we are perceived not to have responded appropriately to their growing concerns around sustainability issues, regardless of whether there is a legal requirement to do so, could also cause reputational harm to our business and could have a material adverse effect on us. For example, if a portion of our operations are perceived to result in high greenhouse gas emissions, our reputation could suffer. In addition, organizations that provide ratings information to investors on sustainability matters may assign unfavorable ratings to Quanta or our industries, which may lead to negative investor sentiment and the diversion of investment to other companies or industries, which could have a negative impact on our stock price and our costs of capital.

Current wording

Certain investors, customers and other stakeholders have focused on sustainability practices of companies, including, among other things, practices with respect to human capital resources, emissions and environmental impact and political spending. Expectations and requirements of our investors, customers and other third parties evolve rapidly and are largely out of our control, and our initiatives and disclosures in response to such expectations and requirements may result in increased costs (including but not limited to increased costs related to compliance, stakeholder engagement, contracting and insurance), changes in demand for certain services, enhanced compliance or disclosure obligations, or other adverse impacts to our business, financial condition, or results of operations. While we have programs and initiatives in place related to our sustainability practices, investors may decide to reallocate capital or to not commit capital as a result of their assessment of our practices. In addition, our customers may require that we implement certain additional procedures or standards in order to continue to do business with us. A failure to comply with investor, customer and other stakeholder expectations and standards, which are evolving and can conflict, or if we are perceived not to have responded appropriately to their growing concerns around sustainability issues, regardless of whether there is a legal requirement to do so, could also cause reputational harm to our business and could have a material adverse effect on us. Moreover, while we may create and publish voluntary disclosures regarding sustainability matters from time to time, many of the statements in those voluntary disclosures are based on hypothetical expectations and estimates and assumptions that may not be representative of current or actual risks or events or forecasts of expected risks or events, including the costs associated therewith. Such expectations and assumptions are necessarily uncertain and may be prone to error or subject to misinterpretation given the long timelines involved and the lack of an established single approach to identifying, measuring and reporting on many sustainability matters. Additionally, we may be subject to new rules that would require companies to provide significantly expanded climate-related disclosures.

Previous wording

A number of factors can also adversely affect the industries we serve, including, among other things, the economic impact of supply chain and other logistical issues, financing conditions, potential bankruptcies and global and U.S. trade relationships and other geopolitical conflicts and other events. A reduction in cash flow or the lack of availability of debt or equity financing for our customers on favorable terms could result in a reduction in our customers’ spending for our services and also impact the ability of our customers to pay amounts owed to us, which could have a material adverse effect on our business, financial condition, results of operations and cash flows. Consolidation, competition, capital constraints or negative economic conditions in the electric power, energy or communications industries can also result in reduced spending by, or the loss of, one or more of our customers.

Current wording

A number of factors can also adversely affect the industries we serve, including, among other things, the economic impact of supply chain and other logistical issues, financing conditions, potential bankruptcies and global and U.S. trade relationships and other geopolitical conflicts and other events. A reduction in cash flow or the lack of availability of debt or equity financing for our customers on favorable terms could result in a reduction in our customers’ spending for our services and also impact the ability of our customers to pay amounts owed to us, which could have a material adverse effect on our business, financial condition, results of operations and cash flows. Negative economic conditions in the electric power, energy or communications industries can also result in reduced spending by, or the loss of, one or more of our customers, including as a result of, among other things, consolidation, competition, capital constraints, concerns regarding the affordability of electricity to end consumers or a decrease in demand for electric power required by large load facilities.

Previous wording

Services within our Underground and Infrastructure segment are exposed to risks associated with the oil and gas industry. These risks, which are not subject to our control, include the volatility of commodity prices and production volumes, the development of and consumer demand for alternative energy sources, and legislative and regulatory actions, as well as public opinion, regarding the impact of fossil fuels on the climate and environment. Specifically, lower prices or production volumes, or perceived risk thereof, can result in decreased or delayed spending by our customers, including with respect to larger pipeline and industrial projects. For example, future restrictions imposed on oil and gas production activities, including as a result of concerns about the impact of climate change, could have a material adverse effect on the oil and gas industry as a whole.

Current wording

Services within our Underground and Infrastructure segment are also exposed to risks associated with the oil and gas industry. These risks, which are not subject to our control, include the volatility of commodity prices and production volumes, the development of and consumer demand for alternative energy sources, and legislative and regulatory actions, as well as public opinion, regarding the impact of fossil fuels on the climate and environment. Specifically, lower prices or production volumes, or perceived risk thereof, can result in decreased or delayed spending by our customers, including with respect to larger pipeline and industrial projects. If our industries were adversely affected, our overall financial position, results of operations and cash flows could also be adversely affected or our stock price could be negatively impacted.

Previous wording

Technological advancements, market developments and other factors may increase our costs or alter our customers’ existing operating models or the services they require, which could result in reduced demand for our services. For example, a transition to a decentralized electric power grid, which relies on more dispersed and smaller-scale renewable energy sources, could reduce the need for large infrastructure projects and significant maintenance and rehabilitation programs, thereby reducing demand for, or profitability of, our services. Additionally, if traditional utilities are unable to meet the electricity demand of certain industries, such as technology or manufacturing companies, it could alter existing operating models and could result in a reduction in demand for our services. Our future success will depend, in part, on our ability to anticipate and adapt to these and other potential changes in a cost-effective manner and to offer services that meet customer demands and evolving industry standards. If we fail to do so or incur significant expenditures in adapting to such change, our businesses, financial condition, results of operations and cash flows could be materially and adversely affected.

Current wording

Technological advancements, market developments and other factors may increase our costs or alter our customers’ existing operating models or the services they require, which could result in reduced demand for our services. For example, a transition to a decentralized electric power grid, which relies on more dispersed and smaller-scale sources, could reduce the need for large infrastructure projects and significant maintenance and rehabilitation programs, thereby reducing demand for, or profitability of, our services. Additionally, if traditional utilities are unable to meet the electricity demand of certain industries, such as technology or manufacturing companies, while maintaining affordability of electric power to end consumers, it could alter existing operating models and could result in a reduction in demand for our services. Our future success will depend, in part, on our ability to anticipate and adapt to these and other potential changes in a cost-effective manner and to offer services that meet customer demands and evolving industry standards. If we fail to do so or incur significant expenditures in adapting to such changes and technological advancements, our businesses, financial condition, results of operations and cash flows could be materially and adversely affected.